City of Brunswick v. Scott.
| Decision Date | 07 April 1924 |
| Docket Number | No. 14837.,14837. |
| Citation | 275 S.W. 994 |
| Parties | CITY OF BRUNSWICK ex rel. BARKWELL v. SCOTT. |
| Court | Missouri Court of Appeals |
Appeal from Circuit Court, Chariton County; J. E. Montgomery, Judge.
Suit on a tax bill issued by the City of Brunswick to George W. Barkwell against Sarah 0. Scott. From a judgment for plaintiff, defendant appeals. Reversed.
F. C. Sasse, of Brunswick, for appellant. Russell Holloway, of Columbia, and Willard P. Cave, of Moberly, for respondent.
This is a suit upon a tax bill issued by the city of Brunswick to plaintiff, Barkwell, purporting to be a lien upon the property of defendant. There was a verdict and judgment in favor of plaintiff in the sum of $355.13, and defendant has appealed.
The bill was issued on the 19th day of November, 1915, for the grading and paving of Broadway street in the city of Brunswick. Another suit was brought on another tax bill issued on other property in the same proceeding. There was a judgment in that case in favor of the relator, Barkwell, resulting in an appeal to this court and the transference of the case to the Supreme Court. That court in City of Brunswick ex rel. Barkwell v. Benecke, 289 Mo. 307, 233 S. W. 169, declared the tax bill void, for the reason that the work was not completed within the time prescribed by the ordinance. In the Benecke Case it was stipulated "that there was no extension of time granted to the contractor for completing this work by ordinance of the city of Brunswick." During the pendency of the appeal in that case no action was taken in the case at bar, but after its decision plaintiff in this case filed an amended reply alleging that the work on the contract was begun on July 28, 1915, and that on the 22d day of September, 1915, the city extended the time for the completion of the work for 60 days additional, and within such time the work was completed and accepted by the city.
The stipulation in the other case is not conclusively binding in this case, and an explanation for the making of the stipulation was given in this case. It is in evidence that Barkwell, who in this case testified that he was present when the extension ordinance was passed with all the formalities required, took sick and was not present at the trial of the former case; that the attorneys examined the record of the proceedings of the city council, and, failing to find that an extension ordinance was granted, entered into the stipulation under the mistaken impression that such ordinance had not been passed.
It is admitted that unless the time for the completion of the work was extended by the board of aldermen on September 22, 1915, the tax bill is void. Without going in detail into the testimony on this subject, it is sufficient to say that there was parol testimony, admitted over defendant's objection, tending to show that an extension ordinance was passed and that it could not be found. But the abstract of the record wholly fails to show that any record was made of the passage of such ordinance. The city clerk testified that he had made search for the ordinance, but had been unable to find it; that he remembered the meeting of the board of aldermen held on September 22, 1915, which Mr. Barkwell attended for the purpose of obtainin an extension of time for the completion of the work; that Barkwell had the application and ordinance prepared; that there was no objection on the part of any one to the extension of time; that the witness kept the minutes of the meeting on a sheet of paper in lead pencil; and that he afterwards placed them in his record book; that at that time the board of aldermen was having a great many meetings, and it was impossible to copy all the minutes in the record book at the time of the meeting; that the minutes of the meeting pad been lost or misplaced and could not be found; that some time after the meeting, the time not being given, he wrote up the record of the meeting from memory, and from information obtained from others. The record that he wrote up shows the presence of the mayor and the number of aldermen present and absent, the allowance of a warrant to a Mr. Van Cleve, and a motion to adjourn the meeting to September 29, 1915. It makes no mention of any extension ordinance. He further testified that he had no recollection as to whether the ordinance was passed.
To continue reading
Request your trial