Busch v. Hart

• Decision Date: 18 April 1896
• Citation: Busch v. Hart, 35 S.W. 534, 62 Ark. 330 (Ark. 1896)
• Parties: BUSCH v. HART
• Court: Arkansas Supreme Court

35 S.W. 534

62 Ark. 330

BUSCH v. HART

Supreme Court of Arkansas

April 18, 1896

Appeal from Garland Circuit Court ALEXANDER M. DUFFIE, Judge.

STATEMENT BY THE COURT.

J. A Busch, on the 28th of December, 1892, entered into a contract with Mark J. Smith to erect a bath house for said Smith in the city of Hot Springs.Busch afterwards sublet a portion of the work to appellee, J. E. Hart, agreeing to pay him therefor the sum of $ 4,100.Hart gave a bond for the performance of his contract, which contained the following conditions, to-wit: "The condition of the above bond is such that, whereas, the said J. E. Hart has this day entered into a contract with the said Jacob A. Busch to furnish certain labor and materials towards the construction of the new Hot Springs Bath House, * * * a copy of which contract is attached hereto and made part hereof: Now, if the said Hart shall well and faithfully perform all the stipulations mentioned and undertaken as set forth in the said contract then this bond shall be void and of no effect; otherwise, in full force and virtue," etc.Hart furnished the material, and completed his contract, and afterwards brought suit against Busch to recover $ 427.50, alleged to be due him upon the contract.Busch alleged that he had paid in full for the work, and, further, that Hart failed to complete the work within the time required by his contract.He alleged that this failure of Hart delayed the completion of the building sixty-six days, and that, by the terms of the principal contract made with Smith, he(Busch) was required to pay damages at the rate of ten dollars for each day of said delay, amounting in all to $ 660.00, which amount he claims that he is entitled to recover from Hart.

Upon the trial, Busch exhibited the bond executed by Hart, above referred to, attached to which bond was a writing.Busch claimed that this was the contract referred to in the bond that it was attached to the bond at the time it was executed and was the contract under which Hart performed his work.This writing was unsigned, but purported to be a contract between Busch and Hart for the performance of the work concerning which this action was brought.It commenced with the following recital, to-wit: "This agreement, made and entered into on this, the day of January, 1893, by and between James E. Hart, party of the first part, and Jacob A Busch, party of the second part, all of Hot Springs, Ark., witnesseth, " etc.

Hart claimed that the contract referred to in the bond was never reduced to writing, while Busch contended that the contract was in writing, and attached to the bond at the time of its execution.The evidence bearing on the question as to whether the contract was attached to the bond at the time of its execution was as follows: Samuel Hamblin, a civil engineer, who superintended the construction of the bath house, testified that Busch and Hart came to him in the first days of January, 1893, and stated that Busch had contracted with Hart to do a portion of the work, and asked him to draw a bond and contract according to their agreement."I made,"he said, "pencil notes of the several points in their verbal agreement, and from them drew the contract.I also drew a bond; both documents being in duplicate, and bound, the bond and contract together, one for each of the contracting parties.I delivered the paper to the parties, who expressed themselves as satisfied with the terms as expressed therein, and took them from me for execution."He identified the bond and contract exhibited in evidence by Busch as one of the set prepared and delivered by him to the parties.Busch, the appellant, testified on this point, and, after reciting the circumstances under which he made the contract with Hart, he proceeds as follows: "Afterwards we called on Col. Hamblin, the superintendent of the building, to draw a contract and bond in accordance with our agreement.He took notes of our agreement, and prepared a bond and contract in duplicate.In each copy the bond and contract were bound together.Both of us expressed ourselves satisfied with the terms of the contract as expressing our agreement, and Hart took them for execution, and returned a copy to me with the bond executed.The bond was signed, and I always supposed the contract was signed until the case came up, when I found that the copy of the contract attached to this bond was not signed.The copy of the contract was attached to the bond just as it is now."Hart testified in his own behalf: "My contract,"he said, "was that the work should be done in a reasonable time, and there was no penalty after any particular date."On cross-examination he was shown the bond signed by him, and testified concerning it: "That he had given this bond to the defendant for the faithful performance of his part of the work.He stated that the form of a contract attached to the bond shown him might have been attached when he delivered the bond, but that he had never signed it, and refused to sign such contract.He was asked to what contract the bond referred, and stated that it was not the one attached, and that there had been no contract signed, and that there was no other, except as he had previously stated."

There was a finding and verdict in favor of plaintiff.

Judgment reversed and cause remanded.

Chas. D. Greaves and Rose, Hemingway & Rose, for appellant.

1.There was no evidence to support the verdict.The contract was attached to the bond, and made part of it by reference to it.A signing of the bond was equivalent to signing the contract.If an unsigned paper is referred to in a paper signed by the party, or is attached to such a paper, it is just as though it was incorporated in the paper signed, and is equivalent to signature.2 Starkey, Ev. 485;1 Reed, St.Fr., sec. 341, 344;2 Whart. Ev., sec. 872;4 N.Y. 144;6 Cow. 448;5 Exch. 631;77 N.C. 88;54 Miss. 483;5 Exch. 907;8 Ala. 546;2 DeG. & Sm. 561;14 N.Y. 584;14 How. 456;18 Ill. 483;15 Me. 40;5 Pick. 395;30 Minn. 389;58 Md. 547;77 Ind. 2;3 Rich. 373;5 Strobh. 129;1 Sneed, 25; 3 Daly, 496;38 N.J.L. 38;9 Allen, 385; 2 Fairfield, 438;33 Barb. 392.

2.But if that were not so, it would make no difference.Hart gave a bond for carrying out the contract, signing the bond himself.Instead of signing the contract, be, in effect, wrote upon it, "I undertake that the within contract shall be performed," and, being the person to perform it, undertook its performance.He cannot escape by saying he did not read it.It was his duty to read it, and he had every opportunity to do so, and he cannot profit by his own neglect.2 Whart. Ev., sec. 1028;117 U.S. 519;78 Ind. 136;6 Blackf. 380;29 Ind. 580;82 Pa.St. 202;3 Ind. 449;18 Kas. 529;100 Ill. 298;79 Ind. 604; 41 Am. 604, and note;48 Ind. 436;56 N.Y. 137;70 Ind. 19;55 N.H. 493;54 Ill. 196;72 Ind. 533;29 Iowa 498;12 Neb.433;118 Mass. 109.

3.The language of the court to defendant was prejudicial to him in the eyes of the jury.59 Ark. 417;49 id. 148;id. 439; 43 id. 73;52 id. 263;43 id. 290.

A. Curl and W. H. Martin, for appellee.

1.The evidence fails to show that the contract was attached to the bond at the time it (the bond) was signed.Appellee testified that he refused to sign the contract, and that his contract with appellant was oral.The architect testifies that appellant refused to sign the contract.There is no expression in the bond that refers to the contract, or identifies it.Hence appellant's contention fails.The attached writing relied on must be clear and certain as to its terms.It must show the contract between the parties.There must be nothing to guess at, nothing to fill in, to make it complete.And it must not be left so as to require oral evidence to explain what is meant, or make it complete.The writing in question was not signed, and no price is named therein for the work.1 H. & N. 473;5 B. &C. 583;2 Whart. Ev., sec. 870.The contract, so-called, was not admissible in evidence.

2.The evidence sustains the claim for extra work.

3.Appellant was not prejudiced by the remark of the judge.It only shows that appellant did not demean himself very well on the witness stand.

Chas. D. Greaves and Rose, Hemingway & Rose, for appellant in reply.

1.It is said there is no proof that the contract was firmly attached to the bond when the bond was signed.

Neither is there any proof that it was not.To have attached a false contract to the bond after its execution would have been a fraud, and a forgery, and the law does not presume fraud,--far less crime.31 Ark. 554;38 id. 419;116 U.S. 615;59 F. 73.

2.The fact that the price or consideration is blank, does not render the contract void, under the statute of frauds, where the contract is executed.Where executed, the statute does not apply, nor has it been pleaded, which is essential.Browne, St. Frauds, sec. 16.In this case there was no...