Dewey Electronics Corp. v. U.S., No. 86-612

CourtUnited States Courts of Appeals. United States Court of Appeals for the Federal Circuit
Writing for the CourtBefore MARKEY, Chief Judge, FRIEDMAN and ARCHER; ARCHER
Citation803 F.2d 650
Parties33 Cont.Cas.Fed. (CCH) 74,611 DEWEY ELECTRONICS CORP., Appellant, v. The UNITED STATES, Appellee. Appeal
Docket NumberNo. 86-612
Decision Date01 October 1986

Page 650

803 F.2d 650
33 Cont.Cas.Fed. (CCH) 74,611
DEWEY ELECTRONICS CORP., Appellant,
v.
The UNITED STATES, Appellee.
Appeal No. 86-612.
United States Court of Appeals,
Federal Circuit.
Oct. 1, 1986.

Page 651

Peter S. Latham, Lewis, Kominers & Jones, Washington, D.C., for appellant.

Elizabeth Woodruff, Commercial Litigation Branch, Dept. of Justice, Washington, D.C., argued for appellee. With her on the brief were Richard K. Willard, Asst. Atty. Gen., David M. Cohen, Director, Howard Lipper and Thomas W. Petersen, Asst. Directors. Harold Kullberg, Office of Counsel, Naval Regional Contracting Center, Washington Navy Yard, Washington, D.C., of counsel.

Before MARKEY, Chief Judge, FRIEDMAN and ARCHER, Circuit Judges.

ARCHER, Circuit Judge.

DECISION

Dewey Electronics Corporation (Dewey) appeals from that portion of the decision, dated June 28, 1985, of the Armed Services Board of Contract Appeals (Board), ASBCA Docket No. 27073, finding the government not liable on four claims for equitable adjustment, pricing of certain items and interest. We affirm.

BACKGROUND

On May 20, 1977, Dewey was awarded a contract with the government to manufacture automatic weather systems (AWS) for the Navy at a firm fixed price. The AWS consisted of two major components: (1) a remote sensor group which included meteorological sensors and data transmission electronics, and (2) a display group which included data reception electronics, digital displays and an analog chart recorder. Peripheral hardware associated with the AWS included a data distribution computer (DDC), an analog computer and a remote display unit. System parts were to be manufactured using government furnished equipment (GFE) in accordance with the specification requirements provided by the government. In attempting to perform the contract, Dewey encountered what it considered to be defects in the contract specification and the GFE which allegedly delayed its performance under the contract and increased its costs.

While not admitting that the GFE or contract specification were defective, the government nonetheless partially terminated the contract for convenience on April 14, 1978, deleting production of certain items in the weather system which required Dewey

Page 652

to copy allegedly defective portions of the GFE. Dewey was advised of this partial termination by telegram and further advised of those items which were not to be terminated under the contract. The telegram was confirmed on April 20, 1978 by a unilateral contract modification containing an incorrect contract number and discrepancies with the earlier telegram as to those items to be terminated. The government corrected the errors on June 2, 1978 by issuing a corrected unilateral contract modification.

Dewey encountered further difficulties in producing the remaining contract items in the AWS, including mechanical problems associated with the dimensions of certain components of other GFE, operational problems in an analog chart recorder obtained from a manufacturing source that the government had allegedly indicated to be reliable, and failure of certain electronic features which were produced in conformance with other GFE that the government had provided.

On February 1, 1979, Dewey submitted a series of claims, which it called a "consolidated claim," to the contracting officer. They consisted of: $149,950.04 for "settlement of the partial termination" effected on April 14, 1978; $389,863.00 as an equitable adjustment for repricing of "unterminated and reordered units"; and $37,421.78 for unabsorbed burden. Included in the consolidated claim was a claim for delay Dewey had suffered due to alleged defects in the GFE model, the costs of which were not segregated and which were stated to be included within both the termination claim and the equitable adjustment claim. 1 By letter dated March 6, 1979, Dewey elected to proceed with its claim under the Contract Disputes Act of 1978 (CDA), Pub.L.No. 95-563, 92 Stat. 2383 (1978) (codified at 41 U.S.C. Secs. 601-613 (1982)).

Dewey was requested by the contracting officer on April 6, 1979 to separate its consolidated claim into each applicable category, i.e., termination claim, delay claim or equitable adjustment claim, but Dewey failed to fully comply with this request. A settlement proposal was submitted by Dewey on October 17, 1979 to the contracting officer covering only the termination claim.

The parties settled the termination claim in January, 1981. The settlement agreement contained the following language to preserve Dewey's right to resubmit the equitable adjustment portion of its 1979 consolidated claim, which Dewey had not submitted separately as it had been instructed to do.

Article 8. Except for the terminated portion of the contract, this agreement does not preclude the contractor from submitting claims, if any, on other matters relating to the contract, including but not limited to claims for contract price increases with respect to the nonterminated units which increases result from the termination and those for equitable adjustment to the contract price under the Changes Clause which result from the following alleged causes:

(a) defective Government furnished property.

(b) changes made by the Contracting Officer.

(d) Government caused delays.

On March 2, 1982, Dewey submitted a certified equitable adjustment claim to the contracting officer seeking an increase in the contract price. It also requested interest, pursuant to 41 U.S.C. Sec. 611, on the equitable adjustment claim which Dewey considered as outstanding since February 2, 1979, when it first submitted its consolidated claim to the contracting officer. This certified filing restated Dewey's February 2, 1979 claims, other than the settled termination claim, and added more claims which were based on facts occurring after February 2, 1979. In all, Dewey's March 2, 1982 submission contained nine separate

Page 653

"claims." 2 The contracting officer did not respond to these certified claims within the time required by 41 U.S.C. Sec. 605(c)(2) (1982), and Dewey therefore filed its appeal with the Armed Services Board of Contract Appeals pursuant to 41 U.S.C. Sec. 605(c)(5) (1982).

On June 28, 1985, the Board issued a decision, limited to consideration of the entitlement issue. It found for Dewey on five claims and remanded them to the contracting officer for "negotiation of the equitable adjustment due appellant." The Board determined that Dewey was not entitled to recover on the four other claims and Dewey now appeals each of these adverse determinations. 3

OPINION

I.

The government has raised, as a jurisdictional matter, 4 the question of whether the decision of the Board constitutes a final decision within the meaning of 28 U.S.C. Sec. 1295(a)(10) (1982). In doing so, it contends that the Board did not fully decide the case before it because five claims were remanded to the contracting officer to determine the amount that should be paid to Dewey on these claims as an equitable adjustment to the contract. The government refers to longstanding concepts of finality, requiring decision on both liability and damages, under 28 U.S.C. Sec. 1291 (1982) relating to appeals from district courts. Reliance is also placed on decisions of our predecessor court involving the effective date of the Contract Disputes Act of 1978. We do not find these to be persuasive and hold that the Board made a final decision on the four claims that are the subject of this appeal and that appeal should not be deferred pending resolution of quantum for the five claims remanded.

Our jurisdiction under 28 U.S.C. Sec. 1295(a)(10) (1982) is to review only final decisions of agency boards of contract appeals. United States v. W.H. Moseley Co., 730 F.2d 1472, 1474 (Fed.Cir.1984). The classical doctrine of finality generally requires that the order below "[end] the litigation on the merits and [leave] nothing for the court to do but execute judgment." Firestone Tire & Rubber Co. v. Risjord, 449 U.S. 368, 373, 101 S.Ct. 669, 673, 66 L.Ed.2d 571 (1981); Coopers & Lybrand v. Livesay, 437 U.S. 463, 467, 98 S.Ct. 2454, 2457, 57 L.Ed.2d 351 (1978); Catlin v. United States, 324 U.S. 229, 233, 6 S.Ct. 631, 633, 89 L.Ed. 911 (1945).

The government points out that, in district court litigation, liability and damages have been treated as parts of a single claim, requiring that both be resolved to have a final decision within the meaning of 28 U.S.C. Sec. 1291 (1982). Liberty Mutual Insurance Co. v. Wetzel, 424 U.S. 737, 744, 96 S.Ct. 1202, 1206, 47 L.Ed.2d 435 (1976). It contends from this that, so long as damages have not been resolved on the claims decided in favor of Dewey, the decision of the Board is not final.

Liberty Mutual, however, dealt only with a single claim for relief. In this case, multiple claims are involved and, while

Page 654

there might be a question as to whether the remanded claims meet the finality requirement, the claims involved in this appeal were decided with finality. See Sears Roebuck & Co. v. Mackey, et al., 351 U.S. 427, 436, 76 S.Ct. 895, 900, 100 L.Ed. 1297 (1956); Cold Metal Process Co., et al. v. United Engineering & Foundry Co., 351 U.S. 445, 452, 76 S.Ct. 904, 908, 100 L.Ed. 1311 (1956). In Sears, the Court noted that the "rule generally followed in the federal courts was that, in a case involving a single plaintiff and a single defendant, a judgment was not appealable if it disposed of some, but less than all, of the claims presented," 351 U.S. at 432, n. 3, 76 S.Ct. at 897, n. 3 and that "Rule 54(b) [Fed.R.Civ.P.] modified the single judicial unit theory but left unimpaired the statutory concept of finality prescribed by [28 U.S.C.] Sec. 1291." Id. at 434, 76 S.Ct. at 899.

The question then is whether the finality concept of district court litigation, requiring both liability and damages to be resolved before an appeal, is applicable to agency board proceedings.

In...

To continue reading

Request your trial
35 practice notes
  • Tyrues v. Shinseki, No. 2013–7007.
    • United States
    • United States Courts of Appeals. United States Court of Appeals for the Federal Circuit
    • October 10, 2013
    ...further proceedings.” Id. at 1376. Elkins is firmly rooted in administrative precedent, such as Dewey Electronics Corp. v. United States, 803 F.2d 650, 656 (Fed.Cir.1986). In Dewey the court held that a rule requiring the full and complete decision of the Armed Services Board of Contract Ap......
  • Tyrues v. Shinseki, 2013-7007
    • United States
    • United States Courts of Appeals. United States Court of Appeals for the Federal Circuit
    • October 10, 2013
    ...further proceedings." Id. at 1376. Elkins is firmly rooted in administrative precedent, such as Dewey Electronics Corp. v. United States, 803 F.2d 650, 656 (Fed. Cir. 1986). In Dewey the court held that a rule requiring the full and complete decision of the Armed Services Board of Contract ......
  • Brownlee v. Dyncorp, No. 02-1601.
    • United States
    • United States Courts of Appeals. United States Court of Appeals for the Federal Circuit
    • November 13, 2003
    ...than, for example, the "rigid district court concept of finality" required by 28 U.S.C. § 1291. Dewey Elecs. Corp. v. United States, 803 F.2d 650, 655 (Fed.Cir.1986) ("Dewey"); see also Rumsfeld v. Applied Cos., 325 F.3d 1328, 1333 n. 3 (Fed.Cir.); cert. denied ___ U.S. ___, 124 S.Ct. 462, ......
  • Wilner v. U.S., No. 92-5161
    • United States
    • United States Courts of Appeals. United States Court of Appeals for the Federal Circuit
    • May 26, 1994
    ...111 S.Ct. 1308, 113 L.Ed.2d 243 (1991) ("The United States ... cannot appeal to the Claims Court."); Dewey Elecs. Corp. v. United States, 803 F.2d 650, 654-55 (Fed.Cir.1986). 11 This was also the case prior to the CDA. See S & E Contractors, Inc. v. United States, 406 U.S. 1, 13, 92 S.Ct. 1......
  • Request a trial to view additional results
35 cases
  • Tyrues v. Shinseki, No. 2013–7007.
    • United States
    • United States Courts of Appeals. United States Court of Appeals for the Federal Circuit
    • October 10, 2013
    ...further proceedings.” Id. at 1376. Elkins is firmly rooted in administrative precedent, such as Dewey Electronics Corp. v. United States, 803 F.2d 650, 656 (Fed.Cir.1986). In Dewey the court held that a rule requiring the full and complete decision of the Armed Services Board of Contract Ap......
  • Tyrues v. Shinseki, 2013-7007
    • United States
    • United States Courts of Appeals. United States Court of Appeals for the Federal Circuit
    • October 10, 2013
    ...further proceedings." Id. at 1376. Elkins is firmly rooted in administrative precedent, such as Dewey Electronics Corp. v. United States, 803 F.2d 650, 656 (Fed. Cir. 1986). In Dewey the court held that a rule requiring the full and complete decision of the Armed Services Board of Contract ......
  • Brownlee v. Dyncorp, No. 02-1601.
    • United States
    • United States Courts of Appeals. United States Court of Appeals for the Federal Circuit
    • November 13, 2003
    ...than, for example, the "rigid district court concept of finality" required by 28 U.S.C. § 1291. Dewey Elecs. Corp. v. United States, 803 F.2d 650, 655 (Fed.Cir.1986) ("Dewey"); see also Rumsfeld v. Applied Cos., 325 F.3d 1328, 1333 n. 3 (Fed.Cir.); cert. denied ___ U.S. ___, 124 S.Ct. 462, ......
  • Wilner v. U.S., No. 92-5161
    • United States
    • United States Courts of Appeals. United States Court of Appeals for the Federal Circuit
    • May 26, 1994
    ...111 S.Ct. 1308, 113 L.Ed.2d 243 (1991) ("The United States ... cannot appeal to the Claims Court."); Dewey Elecs. Corp. v. United States, 803 F.2d 650, 654-55 (Fed.Cir.1986). 11 This was also the case prior to the CDA. See S & E Contractors, Inc. v. United States, 406 U.S. 1, 13, 92 S.Ct. 1......
  • Request a trial to view additional results

VLEX uses login cookies to provide you with a better browsing experience. If you click on 'Accept' or continue browsing this site we consider that you accept our cookie policy. ACCEPT