Rehearing
Granted Dec. 21, 1911.
Appeal
from Law and Equity Court, Mobile County; Saffold Berney
Judge.
Action
by Edward G. Fike against Georgia K. Stratton to enforce a
materialman's lien. From a judgment for insufficient
damages, plaintiff appeals. Affirmed.
The
complaint declares for $1,015 on account for work and labor
and for materials furnished in remodeling and improving a
residence. The complaint sets forth property on which the
lien is claimed, with the further averment that the plaintiff
was the original contractor with the defendant or her agent
for doing the work, and that the defendant is owner of the
premises, and that the work was done under a contract between
the owner or her agent and the said Fike as the original
contractor, and that the contract was for the remodeling and
completion of said residence and for doing other work. Then
follows a statement as to the filing of the verified
statement, etc.
Plea
was as follows:
"And
for further plea in this behalf, defendant says that the
work done and materials furnished and put upon the property
of the defendant was done and furnished under the terms of
a written contract made and entered into by and between
plaintiff and defendant on September 1, 1906, and in which
said written contract, a copy of which is made 'Exhibit
A' to this plea, it was stipulated that the painting of
the exterior of the building to be remodeled and enlarged
was to be substantially and in accordance with the painting
upon the exterior of an adjacent residence of defendant
and this obligation of said written contract was broken by
the plaintiff, in that he had failed and refused to so
paint the house he contracted to remodel and enlarge, and
the defendant avers that the costs of doing this painting
in accordance with the contract amounts to the sum of $143.
And defendant further avers that, in accordance with the
terms of said written contract, the exterior doors upon
said building were to be what is known as 'built-up
doors,' but the defendant avers that the exterior doors
put in said house by plaintiff were not built-up doors, and
the defendant avers that the contract required the placing
of six built-up doors, and that the difference in the value
of six doors as furnished by the plaintiff and the built-up
doors he was required to furnish under the contract was
$2.50 each, making a total of $15. And the defendant
further avers that, under the terms of said written
contract, the said six built-up exterior doors were to be
hung upon three 5X5 bronze butts, but the defendant avers
that these doors were not so hung, being hung on two butts
to the damage of defendant in the sum of $3. And defendant
avers that in said contract it was stipulated that the lock
sets upon the six doors next above referred to were to cost
not less than $8 each. * * * The defendant avers that the
lock set on the door at the entrance to the building cost
about $6, instead of $8, as specified in said written
contract, and the lock sets placed upon the other five
doors cost approximately 50 cents each per set, causing a
loss or damage to the plaintiff in the sum of $39.50. And
the defendant avers that, according to the terms of the
said written contract, all exterior work upon the building
to be remodeled and enlarged was to be of cypress lumber,
and defendant avers that the work upon the exterior as done
by the plaintiff was in pine wood and in violation of said
contract to the damage of the defendant in the sum of $50.
The defendant avers that two front windows were not put in
by plaintiff according to the specifications forming a part
of said written contract, and the change made and
contracted for by the defendant to comply with the
specifications will cost the defendant the sum of $65.
Defendant avers that, under the terms of the said written
contract, the plaintiff was to furnish a bathtub as
specified, and plaintiff failed or refused to put in place,
or rather to furnish this bathtub to the damage of the
defendant in the sum of $62.50. And the defendant avers
that, under the terms and condition of the said written
contract, plaintiff was to furnish lavatories, which he
refused and neglected to do, to the damage of the defendant
in the sum of $18. And the defendant avers that, under the
terms and conditions of the said written contract, the
front door to said building and the windows were to be
plate glass, but the defendant avers that the glass put in
said front door and into said windows was not in accordance
with said contract, to the damage of the defendant in the
sum of $24, and the defendant claims further damages from
the fact that the specifications forming a part of said
contract have not been followed, but, on the contrary,
departed from, and numerous substitutions have been made
for materials specified in said specification, to the
damage of the defendant in the sum of $200. Wherefore the
defendant claims said sum of $620 in the aggregate of the
breaches of said contract by the plaintiff as in this plea
shown, as a recoupment against the demand of the plaintiff.
"(3)
And for further plea in this behalf defendant says to the
entire complaint that under the terms and conditions of a
certain written contract entered into by and between the
plaintiff and the defendant, a copy of which is made
'Exhibit A' to this plea, it was agreed that said
work is to be completed and the building turned over to said
Hamilton or his principal on or before the 20th day of
December, 1906. Should said building not be turned over
complete, said Hamilton may retain out of the compensation
hereinabove provided for the sum of $10 a day until the
building is so turned over, delays beyond contractor's
control excepted. And the defendant avers that the contract
in question was dated September 1, 1906, and said stipulation
above set out was agreed upon as liquidated damages for
failure to turn over and complete said building in accordance
with said written contract, and the defendant avers that the
plaintiff has not to this day completed the said building
according to the contract, and did not turn over the keys of
the same to her or her agent until the last part of July,
1907, wherefore the defendant claims that the plaintiff under
said provision of said contract was indebted to her in the
sum of $1,000 as liquidated damages for failure to complete
and turn over to her or her agent said building within the
time agreed upon, and forming a part of the essence of the
said written contract. Wherefore the defendant claims and
demands a recoupment against the demand of the plaintiff, the
aggregate of the sums set up and claimed by the defendant
against the plaintiff in her pleas numbered 2 and 3 amounting
to $1,620, and she claims judgment for the excess."
The
demurrers to plea 2 were that the contract is not set out
literally or in substance, because it purports to be a plea
of set-off, and does not describe the defendant's demand
by its date, nor state when the same was payable, nor to whom
payable; and because it does not show that at the time the
action of plaintiff was commenced that plaintiff was indebted
to the defendant in any sum whatsoever. Demurrers were also
interposed to each special plea for damages in such case (1)
because it is not shown that the plaintiff obligated himself
to do the particular thing alleged to have been left undone,
or to do them differently from the way they were done, and
because the matters set up are not the proper measure of
damages. Demurrers were interposed to the third plea on
practically the same grounds as above set forth, and because
the plea claims for certain damages for failure to turn over
a certain building to the defendant within a certain time,
and does not show any data by which any damages could be
arrived at, nor does it show any contract obligating
plaintiff to pay any special damages; because it alleges time
as the essence of the contract, and does not show the terms
of the contract whereby the court may determine whether or
not time is of its essence. It may be remarked that the
contract was attached as an exhibit to both pleas. These
pleas were afterwards amended so as to include the written
contract therein, and the allegations of the pleas were
somewhat enlarged, but no material change was made.
The
third clause in the contract was as follows: "Said work
is to be completed and the building to be turned over to said
Hamilton or his principal on or before the 20th day of
December, 1906. Should said building not be turned over
complete, said Hamilton may retain out of the compensation
hereinbefore provided for the sum of $10 per day until the
building is so turned over, delays beyond contractor's
control excepted." The following are replications 10 and
11:
"(10)
Plaintiff said in replication to the third and fourth pleas
that his failure to complete and turn over the dwelling
house to the defendant, mentioned in this contract, the
basis of this suit, within the time ending December, 20,
1906, was not a breach of said contract, in this: that all
the delay after the date in so completing and turning over
said dwelling house to defendant was beyond plaintiff's
control.
"(11)
Plaintiff for replication to the third and fourth pleas
says that his failure to complete and turn over to the
defendant the dwelling house mentioned in the contract, the
basis of this suit, within the time ending December 20,
1906, was not a breach of said contract, in this: That the
contract provided that delays beyond the contractor's
control were excepted from the time for which he was
chargeable with damages, and plaintiff says that all the
delays after that said date in so completing and turning
over said
...