Mcpherson Builders, Inc. v. Performance Premises, LLC

• Decision Date: 04 April 2019
• Docket Number: 526951
• Citation: Mcpherson Builders, Inc. v. Performance Premises, LLC, 171 A.D.3d 1270, 97 N.Y.S.3d 766 (N.Y. App. Div. 2019)
• Parties: MCPHERSON BUILDERS, INC., Appellant, v. PERFORMANCE PREMISES, LLC, Respondent, et al., Defendant.
• Court: New York Supreme Court — Appellate Division

171 A.D.3d 1270

97 N.Y.S.3d 766

MCPHERSON BUILDERS, INC., Appellant,

v.PERFORMANCE PREMISES, LLC, Respondent, et al., Defendant.

526951

Supreme Court, Appellate Division, Third Department, New York.

Calendar Date: February 14, 2019

Decided and Entered: April 4, 2019

Coughlin & Gerhart, LLP, Ithaca (Dirk A. Galbraith of counsel), for appellant.

The Crossmore Law Office, Ithaca (Edward Y. Crossmore of counsel), for respondent.

Before: Clark, J.P., Mulvey, Aarons, Rumsey and Pritzker, JJ.

MEMORANDUM AND ORDER

Aarons, J.

In October 2016, plaintiff entered into a contract with defendant Performance Premises, LLC (hereinafter defendant) wherein plaintiff would provide labor and materials in connection with the first phase of the construction of a steel building on defendant's premises. Defendant intended to use the building as a performance arts and events venue. The contract contained a time is of the essence clause stating that plaintiff "shall substantially complete the [w]ork, no later than [85] days from the date of commencement" of the project – in this case, by December 30, 2016. When plaintiff did not substantially complete its work by this date, defendant did not terminate the contract. Rather, defendant permitted plaintiff to continue with its work, which was ultimately completed in May 2017. Defendant, however, did not pay plaintiff for its work expended after December 30, 2016.

In July 2017, plaintiff filed a notice of mechanic's lien asserting that it was owed $94,810. Plaintiff thereafter commenced this action to foreclose on its mechanic's lien. Defendant answered and asserted as an affirmative defense that plaintiff breached the contract by failing to comply with the time is of the essence clause in the contract. Defendant also asserted a counterclaim alleging that, as a consequence of plaintiff's breach of the contract, it incurred damages in the form of lost profits. After plaintiff submitted a reply to defendant's counterclaim, it moved for summary judgment on its claim and for dismissal of defendant's counterclaim. In April 2018, Supreme Court denied plaintiff's motion. Plaintiff appeals. We affirm.

We conclude that Supreme Court correctly denied that part of plaintiff's motion seeking summary judgment on its claim against defendant. It is undisputed that plaintiff did not comply with the contractual provision requiring that there be substantial completion by December 30, 2016. It is also undisputed that defendant allowed plaintiff to continue to work past this date. By doing so, plaintiff asserts that defendant waived any claim for damages. We disagree. Although defendant would be estopped from relying on plaintiff's failure to substantially complete its work by December 30, 2016 as a basis for terminating or rescinding the contract (see General Supply & Constr. Co. v. Goelet , 241 N.Y. 28, 36–37, 148 N.E. 778 [1925] ; Schenectady Steel Co. v. Trimpoli Gen. Constr. Co. , 43 A.D.2d 234, 237, 350 N.Y.S.2d 920 [1974], affd 34 N.Y.2d 939, 940–941, 359 N.Y.S.2d 560, 316 N.E.2d 875 [1974] ), defendant did not waive any claim to damages caused by such failure (see General Supply & Constr. Co. v. Goelet , 241 N.Y. at 36–37, 148 N.E. 778 ; Deeves & Son v. Manhattan Life Ins. Co. , 195 N.Y. 324, 330, 88 N.E. 395 [1909] ). In this regard, once substantial completion of the work by plaintiff was not completed by December 30, 2016, "[n]othing [plaintiff] ... could possibly do would wipe out the damage" suffered by defendant ( General Supply & Constr. Co. v. Goelet , 241 N.Y. at 36, 148 N.E. 778 ). Indeed, as an affirmative defense to plaintiff's claim, defendant asserted that plaintiff breached the contract when it failed to comply with the time is of the essence provision. As such, although plaintiff is entitled to recover for its work performed after December 2016, any recovery is to be offset by any damages sustained by defendant due to plaintiff's failure to meet the required deadline as set forth in the contract (see id. at 36–37, 148 N.E. 778 ; D'Onfro v. State of New York , 270 App.Div. 9, 13, 59 N.Y.S.2d 205 [1945] ). Furthermore, because plaintiff's claim is inextricably interwoven with defendant's counterclaim for lost profits, plaintiff is not entitled to summary judgment on its claim (see Boston Concessions Group v. Criterion Ctr. Corp. , 200 A.D.2d 543, 544, 606 N.Y.S.2d 696 [1994] ; compare Hussey v. Leggio Agency , 299 A.D.2d 690, 691–692, 750 N.Y.S.2d 345 [2002] ).

Nor are we persuaded by plaintiff's assertion that termination of the contract was defendant's sole remedy once plaintiff did not achieve substantial completion. The contract stated that, if plaintiff was "guilty of substantial breach of a provision of the [c]ontract [d]ocuments," defendant "may terminate the [c]ontract." In view of this permissive language, defendant had the option to terminate the contract, but was not required to do so.

We also...