U.S. for Use and Ben. of Heller Elec. Co., Inc. v. William F. Klingensmith, Inc.

• Decision Date: 02 February 1982
• Docket Number: No. 80-2250,80-2250
• Citation: 670 F.2d 1227,216 U.S.App.D.C. 408
• Parties: , 29 Cont.Cas.Fed. (CCH) 82,194 UNITED STATES of America For the Use and Benefit of HELLER ELECTRIC CO., INC., et al. S. E. B. Masonry, Inc., Appellant, v. WILLIAM F. KLINGENSMITH, INC., et al.
• Court: U.S. Court of Appeals — District of Columbia Circuit

Page 1227

670 F.2d 1227

216 U.S.App.D.C. 408, 29 Cont.Cas.Fed. (CCH) 82,194

UNITED STATES of America For the Use and Benefit of HELLER ELECTRIC CO., INC., et al. S. E. B. Masonry, Inc., Appellant, v. WILLIAM F. KLINGENSMITH, INC., et al.

No. 80-2250.

United States Court of Appeals District of Columbia Circuit.

Argued Sept. 10, 1981.

Decided Feb. 2, 1982.

Appeal from the United States District Court for the District of Columbia (D.C. Civil Action No. 79-03209).

Leslie Yu, Washington, D. C., with whom Christopher M. Kerns, Washington, D. C., was on the brief for appellant.

Michael J. Goergen, Washington, D. C., with whom Branko Stupar, Washington, D. C., was on the brief for appellees.

Before BAZELON, Senior Circuit Judge, and WILKEY and EDWARDS, Circuit Judges.

Opinion for the Court filed by Senior Circuit Judge BAZELON.

BAZELON, Senior Circuit Judge:

This is a Miller Act ¹ action brought in the name of the United States for the use and benefit of SEB Masonry, Inc. (SEB) against William F. Klingensmith, Inc. (Klingensmith) and its Sureties, Fireman's Fund Insurance Co. (Fireman's Fund) and Hanover Insurance Co. (Hanover). SEB appeals a district court ruling ² limiting the amount of damages recoverable in a contract dispute with Klingensmith. Klingensmith and SEB were the general contractor and subcontractor, respectively, on two construction projects-the parking garage and the Allied Health Building-at the Van Ness campus of the University of the District of Columbia. ³ Fireman's Fund was the surety on the parking garage and Hanover was the surety on the Allied Health Building.

I. BACKGROUND

On April 29, 1977 and October 12, 1977, respectively, the United States General Services Administration awarded defendant William F. Klingensmith, Inc. contracts to build the parking garage and the Allied Health Building at the Van Ness campus of the University of the District of Columbia. ⁴ The expected date of completion for the garage was February 12, 1978. ⁵ At that point, work was to begin on the Allied Health Building, which was to be built on top of the parking garage. Klingensmith subcontracted to SEB the masonry work on each building. SEB began work on the parking garage in November 1977 and expected to complete its work within 90 calendar days. ⁶ As it turned out, SEB did not complete the job until October 1978. ⁷ Each party blamed the other for delaying completion of the project, and Klingensmith withheld $16,906.53 from the amount it owed SEB. ⁸

After work on the parking garage was complete, SEB began work on the Allied Health Building. After working for three days in May 1979, SEB left the site and refused to return. In June 1979, Klingensmith terminated its agreement with SEB and hired Pentek Corp. to do the masonry work for $14,398 more than its contract with SEB provided. ⁹

II. THE DISTRICT COURT'S DECISION

SEB filed this action against Klingensmith and its sureties, seeking damages for Klingensmith's delay on the parking garage, and for lost anticipated profits on the Allied Health Building contract. Klingensmith counterclaimed against SEB for delaying work on the parking garage and the Allied Health Building, and for breaching its contract for work on the Allied Health Building. ¹⁰ After trial, the district court found that Klingensmith had delayed the completion of the parking garage. Specifically, it found that Klingensmith had failed to coordinate adequately the work of its subcontractors and that it failed to provide sufficient supervisory personnel on the job. The court also found, however, that SEB contributed to the delay and concluded, therefore, that neither party could collect delay damages from the other. In addition, the district court found that SEB was unjustified in failing to complete its work on the Allied Health Building, and that it had, therefore, breached its contract with Klingensmith. ¹¹ Accordingly, the district court ruled that SEB owed Klingensmith $14,398-the difference between the original contract price and Pentek's contract price. That amount was deducted from the $16,906.53, which Klingensmith still owed SEB for work on the garage, and the court entered a judgment against Klingensmith and Fireman's Fund for $2,508.53. ¹²

III. ANALYSIS

SEB argues that the district court erred in refusing to award damages for Klingensmith's delay, even though SEB may have been partially responsible for the delay. SEB contends that the district court should have determined the extent to which each party was harmed as a result of the other party's delay, and apportioned the damages accordingly. In addition, SEB urges that the district court erred in ruling that it had breached its contract to do the masonry work on the Allied Health Building. We agree with SEB with respect to delay damages on the parking garage contract, but we agree with the district court's conclusion that SEB breached the Allied Health Building contract.

A. Damages for Delay

As stated above, the district court found that Klingensmith had violated its contractual obligations by delaying SEB's work on the parking garage. Klingensmith asserts that the district court's finding is invalid as a matter of law because its subcontract with SEB contained no completion date. We disagree. In a construction contract like the subcontract at issue here, the prime contractor implicitly promises to provide such working conditions as may be necessary to allow its subcontractor to carry out its obligations under the contract. Burgess Construction Co. v. M. Morrin & Son Co., Inc., 526 F.2d 108, 113 (10th Cir. 1975); George A. Fuller Co. v. United States, 69 F.Supp. 409 (Ct.Cl.1947). ¹³ If a contractor interferes with the work of its subcontractor, it has breached its obligation, and the subcontractor is entitled to recover for the resulting delays. George A. Fuller v. United States, supra. We, therefore, affirm this aspect of the district court's decision.

In addition to finding that Klingensmith had delayed SEB's work on the parking garage, the district court found that SEB had delayed the completion of both the garage and the Allied Health Building. The court did not, however, evaluate each party's claim for delay. Instead, it concluded, as a matter of law, that neither party could recover for the other party's delay. In so doing, the district court erred.

There is no doubt that if only one party had delayed, that party would have been liable to the other for damages. See, e.g., United States ex rel. Gray-Bar Electric Co., Inc. v. J. H. Copeland & Sons Construction, Inc., 568 F.2d 1159 (5th Cir. 1978); United States ex rel. Mariana v. Piracci Construction Co., Inc., 405 F.Supp. 904 (D.D.C.1975); United States ex rel. Otis Elevator Co. v. Piracci Construction Co., Inc., 405 F.Supp. 908 (D.D.C.1975). In a case like this, where each party delays the other, it follows that each should be able to recover to the extent of the injury caused by the other's delay. ¹⁴ Such a rule protects each party from losses due to the delay of the other throughout the period of performance. It also induces each party to avoid imposing such losses on the other at any time during the period of performance. In contrast, a rule precluding a party from recovering damages for delay, once the party itself delays, would leave the parties to a contract unnecessarily vulnerable to delay by the other. We see no wisdom in, nor authority for, such a rule of preclusion. Therefore, when both parties to a contract breach their contractual obligations by delaying performance, a court must assess the losses attributable to each party's delay and apportion damages accordingly.

A plaintiff claiming, or a defendant counterclaiming, delay damages must prove, first, the amount of delay caused by the other party, ¹⁵ and second, the amount of damages attributable to such delay. In this case, therefore, SEB can recover whatever damages that it proves Klingensmith to have caused, minus the amount of damages Klingensmith proves SEB to have caused. ¹⁶

B. Breach of the Allied Health Building Contract

As stated above, the district court concluded that SEB had breached its contract with Klingensmith to build the Allied Health Building. The court supported is conclusion with findings that SEB had failed to return to the job after May 1977, that SEB failed to notify Klingensmith of its intentions regarding completion of the work, and that SEB was working on another project when it was supposed to be working on the Allied Health Building. ¹⁷ In addition, the evidence showed that on March 12, 1979, SEB had reaffirmed its intent to perform its obligations under the Allied Health Building contract, ¹⁸ and that Klingensmith had repeatedly and unsuccessfully attempted to prompt SEB to complete performance. ¹⁹ We do not find the district court's findings of fact clearly erroneous. Nor do we find error in its conclusion of law. Therefore, we affirm this aspect of the district court's decision.

C. Liability of Surety Under the Miller Act

As section A of this opinion establishes, Klingensmith may be held liable to SEB for the net cost of each party's delay in completing the parking garage. The issue arises, therefore, whether Fireman's Fund, Klingensmith's surety on the parking garage contract, can be held liable for those damages. We conclude that, under the Miller Act, it can. ²⁰

Section 1(a)(2) of the Miller Act ²¹ requires that government contractors must furnish payment bonds for the protection of subcontractors that provide labor and materials for work on government contracts. ²² Section 270b(a) of the Act provides that (e)very person who has furnished labor or material in the prosecution of the work provided for in such contract, in respect of which a payment bond is furnished under section 270a of this title and who has not been paid in full therefor before the expiration of a period of ninety days after the day on which the last of the labor was done or performed by...