Airflex Industrial, Inc. v. Fifth @ 42nd LLC, 2008 NY Slip Op 30792(U) (N.Y. Sup. Ct. 3/19/2008)
| Decision Date | 19 March 2008 |
| Docket Number | No. 0601851/2006.,Motion Seq. No. 01.,0601851/2006. |
| Citation | 2008 NY Slip Op 30792 |
| Court | New York Supreme Court |
| Parties | AIRFLEX INDUSTRIAL, INC., Plaintiff, v. FIFTH @ 42<SUP>ND</SUP> LLC, Defendant. [and three third-party actions] |
This action arises from a dispute between plaintiff Airflex Industrial, Inc. and defendant-counterclaimant Fifth @ 42nd LLC relating to a construction project. Defendant moves pursuant to CPLR 3025(b) for leave to amend its counterclaims against plaintiff and to assert a claim against two of plaintiff's principals, Frederick Fogelman and Jonathan Fogelman, for willful exaggeration of the mechanic's lien that has been filed against defendant.
The court derives the following factual allegations from the complaint:
Defendant owns real property located at 505 Fifth Avenue, New York, New York. Plaintiff is in the business of fabricating and installing specialty metal products for high-end construction projects.
In July 2004, defendant's agent and construction manager, Pavarini-McGovern LLC ("Pavarini"), approached plaintiff to submit a bid to provide the exterior metal panel wall system, together with other miscellaneous metal, for a construction project at the defendant's property. Pavarini accepted plaintiff's bid for the project on behalf of defendant, and on August 24, 2004, the parties entered into a contract for, among other things, the fabrication and installation of the panel wall system. The lump sum price listed in the contract was $2,040,000.
After entering into the contract, plaintiff produced and submitted shop drawings to Pavarini, defendant, and the "Design Team," which consisted of the architect and the structural engineer. The shop drawings demonstrated, among other things, how plaintiff intended to construct the panel wall system to meet the requirements of the set of plans and specifications for the project dated August 9, 2004 ("Contract Documents"). Pavarini, defendant, the Design Team, and Gordon H. Smith Corporation, an exterior wall consultant, approved the shop drawings.
In late March 2005, when plaintiff arrived on the project site to begin its work pursuant to Pavarini's directions, the project was not ready for plaintiff to commence work. Prior to plaintiff's arrival, defendant's surveyor, Lovell & Belcher, set marks and benchmarks to indicate the required location of the face of the panel wall system. Pavarini directed plaintiff to construct its panel wall system so that the face of it matched the marks and benchmarks that Lovell & Belcher set. Using those marks and benchmarks, and as required pursuant to the contract, plaintiff conducted a field survey to measure the distance from the required face of the panel wall system to the concrete shear walls that formed a vertical surface and to the framed walls that formed each floor of the project (collectively, "Structural Elements"). Upon conducting this field survey, plaintiff found materially different field conditions than those specified in the Contract Documents.
The field survey revealed that the Structural Elements were improperly located, thereby rendering it impossible for plaintiff to install its panel wall system pursuant to the Contract Documents or its approved shop drawings. The condition and location of the Structural Elements, as constructed, allegedly required plaintiff to perform extensive extra work in order to install the panel wall system properly.
Plaintiff claims to have promptly informed Pavarini of the deficiencies in the Structural Elements and gave notice that plaintiff would have to revise extensively the panel wall system over and above the work under the contract in order to overcome the Structural Elements. Plaintiff then received directions to devise and implement a solution so as to allow plaintiff to install the face of its panel wall system at the marks and benchmarks set by Lovell & Belcher while accommodating the location of the Structural Elements. Plaintiff also received directions to perform extra work on the project in order to accommodate defendant's tenant and meet the target date of August 15, 2005 for the issuance of a temporary certificate of occupancy. Plaintiff submitted revised shop drawings to Pavarini, defendant, and the Design Team. Pavarini, defendant, the Design Team, and the Exterior Wall Consultant approved the revised shop drawings, and plaintiff was informed of this approval on June 30, 2005.
Defendant directed and authorized plaintiff to proceed with the extra work that consisted of, among other things, the design, fabrication, and installation of a revised mounting system and overtime, acceleration, and other additional costs. Defendant repeatedly promised to pay plaintiff for the extra work. In consideration for plaintiff performing the extra work, defendant ceased paying plaintiff pursuant to the terms of the contract, and instead began paying plaintiff on a weekly basis. Plaintiff repeatedly informed defendant that its weekly payments were insufficient and that additional payments were necessary to fully compensate plaintiff for the extra work. On December 20, 2005, defendant ceased its weekly payments to plaintiff. Since that time, defendant has repeatedly refused to pay plaintiff for the extra work.
Plaintiff Airflex Industrial, Inc. brings four causes of action against defendant, namely: (1) foreclosure of its mechanic's lien against the property; (2) quantum meruit; (3) unjust enrichment; and (4) breach of contract. Plaintiff seeks $4,513,576, plus interest, for each cause of action.
In its answer, defendant Fifth @ 42nd LLC asserts four counterclaims against its former subcontractor. The first three counterclaims are for breach of contract and the fourth counterclaim seeks to void plaintiff's mechanic's lien pursuant to Lien Law § 39 because of willful exaggeration and an award of damages pursuant to Lien Law § 39-a. Defendant contends that it has complied with plaintiff's contract in every respect and, in fact, was forced to pay plaintiff a total of $2.7 million, because plaintiff claimed that it could not pay its labor force to complete the job properly and threatened to walk off the job.
Defendant now seeks to amend its counterclaims against plaintiff and to add the Fogelmans as counterclaim-defendants. Defendant's attorney contends that discovery has revealed that a substantial portion of the additional $4.5 million plaintiff seeks to recover is for monies allegedly due and owing to the Fogelmans, individually, as financing costs associated with advances the Fogelmans purportedly made in 2006 to alleviate plaintiff's cash flow problems. Defendant maintains that the Fogelmans did not make these advances to benefit the project, and costs incurred as a result of these advances were wrongfully included in the lien that plaintiff filed. Defendant now seeks to amend its counterclaims to assert additional factual allegations in support of its claim against plaintiff for willful exaggeration of the lien and also to assert this claim against the Fogelmans, individually, under a corporate veil-piercing theory.
Plaintiff first contends that defendant has failed to submit sufficient evidence in support of its motion.
A motion for leave to amend pleadings "must be supported by an affidavit of merits and evidentiary proof that could be considered upon a motion for summary judgment." Nab-Tern Constructors v. City of New York (Yankee Stadium), 123 A.D.2d 571, 572-573 (1st Dept. 1986); see also Marinelli v. Shifrin, 260 A.D.2d 227, 229 (1st Dept. 1999). An attorney's affirmation is acceptable if "the attorney has personal knowledge of the facts upon which the motion is based [citation omitted]." Davidowitz v. Dixie Assocs., 59 A.D.2d 659 (1st Dept. 1977); see also Parametric Capital Mgt., LLC v. Lacher, 33 A.D.3d 376, 376 (1st Dept. 2006).
Defendant submits initial and reply affirmations of its attorney, the proposed Verified Answer and Amended Counterclaims,* plaintiffs responses to interrogatories, and other documentary evidence obtained during discovery that reveal new facts giving rise to this application. As defendant's attorney was involved in discovery for this case, he has personal knowledge of the documents that plaintiff produced and which give rise to new facts forming the basis of this motion. Although defense counsel's initial affirmation does not state the material facts supporting the proposed amended counterclaims, his reply affirmation details the facts and circumstances that motivated this motion. From plaintiff's responses to interrogatories and the financial documents that plaintiff and its certified public account produced, defendant asserts that a substantial portion of the $4,513,576 lien that plaintiff filed consists of interest on personal loans that the Fogelmans made to plaintiff in 2006.
Plaintiff next contends that the defendant cannot show that it would be successful on a claim under sections 39 and 39-a of the Lien Law against the Fogelmans individually.
Under New York law, on a motion for leave to amend pleadings, "the proponent must allege legally sufficient facts to establish a prima facie cause of action or defense in the proposed amended pleading." Daniels v. Empire-Orr, Inc., 151 A.D.2d 370, 371 (1st Dept. 1989). When the proposed amendment "clearly lacks merit and serves no...
To continue reading
Request your trial