Batson-Cook Co. v. Loden & Co., Inc.
Decision Date | 13 July 1973 |
Docket Number | No. 1,No. 48318,BATSON-COOK,48318,1 |
Citation | 199 S.E.2d 591,129 Ga.App. 376 |
Parties | COMPANY v. LODEN & COMPANY, INC |
Court | Georgia Court of Appeals |
Syllabus by the Court
1. On an action by a subcontractor against a contractor for extra compensation based on the theory that extraordinarily rigid requirements by the architect and inspectors caused the plaintiff extra labor and expense in culling out bricks, a fact issue was presented as to whether the requirements accorded with or were higher than those in the general specifications. The evidence was sufficient to authorize a verdict in favor of the plaintiff.
2. A portion of the charge not excepted to in the trial court will not be considered by this court.
3. The testimony of the plaintiff's executive officer in charge of performance of the contract was properly admitted, the amount of damages was supported by proof, and the plaintiff was not precluded from prosecuting this claim because of failure to comply literally with certain provisions in the general contract relating to proof of claim.
The plaintiff Loden & Company, Inc. was a subcontractor of Batson-Cook Co., a general contractor employed by the City of Atlanta to construct the Lakewood Stadium, and, in particular as regards this lawsuit, to lay certain brick walls. Prior samples were offered for inspection. The parties were then informed by the architect that the sample was approved The defendant, referring to the architect's recommendation, then wrote the plaintiff who had forwarded and endorsed the decision: The plaintiff replied, pointing out that this would involve extra culling of bricks and would result Defendant replied that
The architect who had written the original letter testified that he had been mistaken taken in informing the plaintiff that no chipped brick should be laid up; what he meant was chips larger than those allowed by the specifications. The plaintiff's job superintendent testified that the inspector insisted on 'no chips'; that inspections were rigid, that 500 to 1000 bricks had to be removed on account of chips, and that, to continue with the work, and meet inspections, all bricks had to be culled and those with more than very minimal chips discarded. Some 144,000 bricks were laid and rejects thrown out, lowered to the ground, restacked, rebanded, and returned to the warehouse. 35,400 bricks were culled out, although not all of these were rejected simply because of chips. A high percentage of the rejects, based on inspection requirements, met standard specifications.
The plaintiff made a claim for extra compensation to the defendant, which referred it to the owner and on its being rejected by the owner in turn refused to pay. This action was then filed, and the jury returned a verdict in favor of the plaintiff from which the defendant appeals.
Glover & Davis, Welborn B. Davis, Jr., Newnan, for appellant.
Archer, Patrick & Sidener, Griffin Patrick, Jr., Charles F. Reeves, East Point, for appellee.
1. The defendant contends that the verdict is not supported by evidence generally because (a) there is no evidence that the plaintiff performed extra work because there is no evidence of excessive chippage; (b) what work the plaintiff performed in this regard was demanded by the original contract specifications and was not extra work; (c) notice of intention to claim extra compensation was not given as required by the contract; (d) no monetary amount of damages was shown. As to the first two contentions, the evidence set out in the statement of facts is sufficient to raise a jury question as to whether or not the plaintiff was held...
To continue reading
Request your trial-
Miller v. Lomax
...infer the existence of facts reasonably and logically consequent on those proved." (Citation omitted.) Batson-Cook Co. v. Loden & Co., 129 Ga.App. 376, 379(3), 199 S.E.2d 591 (1973). Carolyn Miller further argues that although the parties to the Settlement Agreement may have been free to ag......
-
Allgood Elec. Co. v. Martin K. Eby Const. Co., 5:93-cv-125-1 (WDO).
...Georgia courts have held that provisions applicable to notice provisions must be reasonably construed. Batson-Cook Company v. Loden & Company, 129 Ga.App. 376, 199 S.E.2d 591 (1973). In Batson-Cook the Georgia Court of Appeals did not bar a claim for additional compensation even though the ......
-
APAC-Georgia, Inc. v. Department of Transp.
...provision and whether DOT waived the requirement. Notice requirements must be reasonably construed. Batson-Cook Co. v. Loden & Co., 129 Ga.App. 376, 378(1), 199 S.E.2d 591 (1973). The key issue is whether DOT had actual notice of the delays for which APAC seeks damages. State Hwy. Dept. v. ......
-
Essentials of Building Construction Contracts
...(La. 1960); see also, S. Hansen Lumber Co. v. De Moss, 253 Ia. 204, 111 N.W.2d 681 (Iowa 1961); Batson-Cook Co. v. Loden & Co., Inc., 129 Ga.App. 376, 199 S.E.2d 591 (1973) (architect far exceeded industry standards in rejecting imperfect bricks); Brooks Towers Corp. v. Hunkin-Conkey Constr......