Fowler v. Island Properties, LLC, 2005-10448.
Decision Date | 27 March 2007 |
Docket Number | 2005-10448.,2006-01452. |
Citation | 2007 NY Slip Op 02699,38 A.D.3d 831,833 N.Y.S.2d 146 |
Court | New York Supreme Court — Appellate Division |
Parties | FOWLER, RODRIGUEZ, KINGSMILL, FLINT, GRAY & CHALOS, LLP, Appellant, v. ISLAND PROPERTIES, LLC, Respondent. |
Ordered that one bill of costs is awarded to the appellant.
In May 1999 the plaintiff's predecessor in interest, the Chalos Law Firm, LLC (hereinafter the Chalos Firm), entered into a written lease with the defendant for office space on the third floor of a commercial building (hereinafter the original lease). In August 2000 the Chalos Firm, in need of room for expansion, entered into a lease with the defendant for additional office space at an adjacent building (hereinafter the second lease). Pursuant to the second lease, the defendant agreed, inter alia, to make substantial improvements, including the construction of an enclosed pedestrian walkway connecting the two properties at the third floor. The term of the second lease was to commence on October 1, 2000, or the date of "substantial completion" of the promised improvements, which was to be determined "at Landlord's sole discretion."
In March 2002 the plaintiff commenced this action, inter alia, to recover damages for breach of the second lease. The plaintiff alleged that, despite due demand, the defendant had failed to timely complete the promised improvements, making occupancy of the additional space impossible, and, in effect, requiring relocation of the Chalos Firm and vacatur of existing leased space.
The defendant answered and moved for summary judgment, inter alia, dismissing the complaint. The defendant noted that section 24 of the second lease exculpated it from all damages arising from a delay in giving possession. In this respect, the defendant asserted that significant unforeseen delays had arisen due to "serious structural problems" with the subject properties, which were revealed only during demolition, and by "a multitude of other...
To continue reading
Request your trial-
Arnell Constr. Corp. v. N.Y.C. Sch. Constr. Auth.
...v. Incorporated Village of Bayville, N.Y. , 44 A.D.3d 807, 810, 843 N.Y.S.2d 681 ; Fowler, Rodriguez, Kingsmill, Flint, Gray & Chalos, LLP v. Island Props., LLC , 38 A.D.3d 831, 833, 833 N.Y.S.2d 146 ). Contrary to the defendant's contention, the plaintiff's failure to notify the defendant,......
-
Tougher Indus., Inc. v. Dormitory Auth. of State
...N.Y.3d 713, 861 N.Y.S.2d 274, 891 N.E.2d 309 [2008]; see Fowler, Rodriguez, Kingsmill, Flint, Gray & Chalos, LLP v. Island Props., LLC, 38 A.D.3d 831, 833, 833 N.Y.S.2d 146 [2007] ). Here, the parties do not dispute that defendant met this initial burden; rather, plaintiff argues that it su......
-
Tougher Indus., Inc. v. Dormitory Auth. of State
...N.Y.3d 713, 861 N.Y.S.2d 274, 891 N.E.2d 309 [2008] ; see Fowler, Rodriguez, Kingsmill, Flint, Gray & Chalos, LLP v. Island Props., LLC, 38 A.D.3d 831, 833, 833 N.Y.S.2d 146 [2007] ). Here, the parties do not dispute that defendant met this initial burden; rather, plaintiff argues that it s......
-
Aurora Contractors, Inc. v. W. Babylon Pub. Library
...York, 58 N.Y.2d 377, 384, 461 N.Y.S.2d 746, 448 N.E.2d 413;Fowler, Rodriguez, Kingsmill, Flint, Gray & Chalos, LLP v. Island Props., LLC, 38 A.D.3d 831, 833, 833 N.Y.S.2d 146). However, “even with such a clause, damages may be recovered for: (1) delays caused by the contractee's bad faith o......