Salzman v. Holiday Inns, Inc.

• Citation: 369 N.Y.S.2d 238,48 A.D.2d 258
• Parties: Sidney J. SALZMAN and Leo Spezio d/b/a River Development Company, Plaintiffs, v. HOLIDAY INNS, INC., Defendant. HOLIDAY INNS, INC., Third-Party Appellant, v. INSTLCORP, INC., Third-Party Respondent.
• Decision Date: 06 June 1975
• Court: New York Supreme Court Appellate Division

Page 238

369 N.Y.S.2d 238

48 A.D.2d 258

Sidney J. SALZMAN and Leo Spezio d/b/a River Development

Company, Plaintiffs, v. HOLIDAY INNS, INC., Defendant.

HOLIDAY INNS, INC., Third-Party Appellant, v. INSTLCORP, INC., Third-Party Respondent.

Supreme Court, Appellate Division, Fourth Department.

June 6, 1975.

Nixon, Hargrave, Devans & Doyle, Rochester, for third-party appellant (Michael T. Tomaino, Rochester, of counsel).

Streppa, Osgood, Cleary, Persons & Gaenzle, Rochester, for third-party respondent (E. Garrett Cleary, Rochester, of counsel).

Before MOULE, J.P., and CARDAMONE, SIMONS, MAHONEY and GOLDMAN, JJ.

MOULE, Justice Presiding.

The question presented on this appeal is whether a contractor who provides interim financing for a construction project may maintain a cause of action as a third party plaintiff against a permanent financer for an alleged breach by the latter of a financing commitment to the owner after the owner sues the contractor, claiming that the contractor's delay in construction was the cause of the damages which accrued as a result of the breach.

The facts of the case are not in dispute. Plaintiffs' predecessor, L.S. & G. Development Corporation (LS & G), was the owner of a parcel of land in the City of Rochester. In January, 1968 it contracted with defendant/third party plaintiff Holiday Inns, Inc. (Holiday) for the latter to construct a 6.2 million dollar, 502 room motor hotel on the site. Holiday was to serve as general contractor for the project and was also to provide interim financing. The agreement was contingent upon LS & G's securing a firm commitment for a permanent mortgage loan by June 15, 1968.

LS & G secured such a commitment from third party defendant Instlcorp on April 19, 1968. The commitment provided that Instlcorp would loan LS & G 7.5 million dollars at 7 3/4 per cent interest upon completion of the project and that such loan was to be secured by a first mortgage on the property. It also provided that construction was to commence on July 31, 1968 and that the loan offer would remain open for 18 months thereafter. Further, it contained a provision whereby an extension would be granted in the event of '(a)ny delay in construction or commencement thereof by reason of force majeure, strikes, civil disorder and/or act of God or any event beyond the control of L.S. & G.'

On May 14, 1969 a letter was sent by the attorneys for plaintiffs' predecessor to Instlcorp requesting that the commitment be extended until August 21, 1970. The letter stated that the project had been delayed due to problems with utility lines, the construction of a retaining wall, and underground site conditions, and that Holiday, as interim financer, and its bank, the Chemical and Security Trust Company, were concerned at the prospect that the delay might affect Instlcorp's commitment for permanent financing.

The record is silent as to Instlcorp's response to this request. However, a letter from Instlcorp to LS & G dated December 15, 1969 indicates that on or about that date Instlcorp and LS & G reached an agreement to amend the commitment to provide for its extension through September 1, 1970 but at an interest rate of 9 per cent rather than the 7 3/4 per cent originally negotiated.

Sometime after the motor hotel project was completed and Holiday was paid, plaintiffs, as successor in interest to LS & G, commenced an action against Holiday seeking 5.5 million dollars in damages for alleged shoddy construction of the facility. Included in its complaint were four causes of action seeking one million dollars in damages as a result of Holiday's failure to complete the work on time, which failure led to LS & G's having to pay a higher rate of interest to assure extension of its permanent financing commitment from Instlcorp. Holiday served an answer denying the allegations of plaintiffs' complaint and setting forth several affirmative defenses and counterclaims. It also served a third party complaint on Instlcorp, claiming to be a third party beneficiary of the permanent financing agreement between Instlcorp and LS & G and that Instlcorp had breached its part of that bargain by refusing to extend the commitment date without extracting a higher interest rate for so doing. In the alternative, Holiday alleged a right of subrogation to LS & G's claim against Instlcorp should LS & G succeed in its action against Holiday and further alleged that should LS & G succeed, Instlcorp, by implied contract with Holiday, would be bound to indemnify Holiday for its losses. Instlcorp moved to dismiss Holiday's third party action on the ground that it failed to state a cause of action. Its motion was granted and Holiday has appealed.

In a memorandum decision accompanying its order dismissing Holiday's complaint, the trial court held that Holiday was not a third party beneficiary of the financing agreement between LS & G and Instlcorp because there was nothing in the agreement indicating an intent to benefit Holiday. The court stated that Instlcorp promised to render performance to LS & G, not to Holiday. If anything, Holiday was only an incidental beneficiary. The court found that since Holiday was not a third party beneficiary, the contracting parties were free to amend their agreement to provide for a higher interest rate without Holiday's consent. It further held, albeit tersely, that Holiday was not entitled to recover either under its subrogation or implied contract theories.

On this appeal Holiday urges that the trial court erred in not finding it to be a third party beneficiary to the permanent financing agreement and also presses arguments in support of its recovery as a subrogee or indemnitee under an implied contract between it and Instlcorp.

The general rule with regard to third party beneficiary contracts is that an intent to confer a direct benefit on a third party must clearly appear in order to enable such a party, not named in the contract, to recover thereunder (Snyder Plumbing and Heating Corporation v. Purcell, 9 A.D.2d 505, 195 N.Y.S.2d 780). The benefit so conferred must not be merely incidental but must be immediate in such a sense and to such a degree as to indicate the assumption of a duty to make reparation if the benefit is lost (Associated Flour Haulers and Warehousemen, Inc. v. Hoffman, 282 N.Y. 173, 26 N.E.2d 7; H. R. Moch Company, Inc. v. Rensselaer Water Company, 247 N.Y. 160, 159 N.E. 896). An incidental beneficiary is a person who may derive benefit from the performance of a contract though he is neither the promisee nor the one to whom performance is to be rendered (2 Williston on Contracts, 3d Ed., § 402). As Williston says, the typical case of an incidental beneficiary is where 'A promises B to pay him money for his expenses. Creditors of B (though they may incidentally benefit by the performance of A's promise) are not generally allowed to sue A' (2 Williston on Contracts, 3d Ed., § 402, Supra).

The Restatement of Contracts, § 133, gives this example: 'B promises A for sufficient consideration to pay whatever debts A may incur in a certain undertaking. A incurs in the undertaking debts to C, D and E. If, on a fair interpretation of B's promise, the amount of the debts is to be paid by B to C, D and E, they are creditor beneficiaries; if the money is to be paid to A in order that he may be provided with money to pay C, D & E, they are not most incidental beneficiaries' (Restatement of Contracts, § 133, Illus. 9).

In the instant situation the agreement between Instlcorp and LS & G called for Instlcorp to pay money to LS & G, not to Holiday. LS & G would then use the money to...